Supply of Property Investment Opportunities

These are the terms and conditions which govern the relationship between REAL Property Scotland Limited (the "Agent") and you, the Customer, for the provision of services (as described below) and incorporate any invoice and/or statement.

These terms and conditions set out the agreed basis upon which we will provide the services to you.

​

Payment of any sums due and/or the receipt of the services from the Agent shall be deemed to constitute acceptance of these terms and conditions.

The terms are as follows:

​

Services

​

The Agent agrees to introduce the Customer to the seller of a property or properties with the intention that the Customer purchases such property or properties from the seller (the "Transactions").

Confidentiality

​

The parties hereby undertake to the other party:

(a) to use information about the other party for the purpose of progressing the Transactions only;

(b) to keep all information between them confidential;

(c) not to disclose any information to any third party without the prior written consent of the Customer; and

(d) to hold all information under the terms of the applicable data protection legislation.

Structure of Transaction

​

The following terms set out how the Transaction will operate between the Customer and the Agent:

- the Customer's appointed solicitor shall submit the formal offer for the property or properties to the Agent at [email protected]

- upon receipt of the formal offer, the Agent shall raise an invoice.

- if the invoice is not paid within 24 hours of issue, the Agent shall be able to sell the Investment Opportunity to another one of its customers.

Fees and Charges

​

The Customer will pay to the Agent the fees and charges for the services provided as set out in the Invoice.

In cases where the Agent or the seller is responsible for the Transaction not being able to proceed, all fees and charges will be credited to Customer account and applied to an alternative Investment Opportunity. No refunds will be provided.

In cases where the Customer withdraws from the transaction for whatever reason, all fees and charges are non-refundable and shall be retained by the Agent.

The Agent, regardless of circumstances, accepts no liability for costs incurred to Customer from any other entity, whether such costs are related to the Transaction or otherwise.

Governing Law and Jurisdiction

​

These terms and conditions shall be governed by the laws of Scotland and the courts of Scotland shall have exclusive jurisdiction to settle any dispute which may arise out of or in connection with them.

By continuing to deal with us or by signing this contract, the Customer understands they are entering into a legally binding agreement.

Supply of property Training Services

These are the terms and conditions which govern the relationship between REAL Property Scotland Limited (”RPS”) and you and incorporate any invoice and/or statement

Payment of any sums due and/or the receipt of services from RPS shall be deemed to constitute acceptance of these terms and conditions.

1. Services

RPS shall provide you with the services as set out in the description of services.

​

2. Payment

You shall pay for the services in accordance with the terms of the invoice and/or statement as applicable.

​

3. Confidentiality

These terms and conditions and any invoice and statement are confidential to the parties.

​

4. Intellectual Property

4.1 RPS owns all intellectual property in all [training materials and documents] in whatever format provided to you.

4.2 You are provided with the [training materials and documents] for the sole purpose of receiving the services.

4.3 You shall not in any circumstance use or reproduce the training materials or documents.

​

5. No financial advice

RPS is not providing you with any advice and no part of the services shall be construed as the provision of advice of any kind.

6. Guarantee

6.1  RPS is providing the services from its own experience and expertise.

6.2 RPS guarantees that if you apply the strategies outlined in our educational content that you will provide yourself with the best opportunity to create: infinite returning assets, a profitable property business, cash flow and increased equity due to capital appreciation over a longer period of time. If you do not put the work in you will NOT achieve these results

6.3 RPS is not liable in cases where you do not apply the strategies, put the work in or where results are not achieved.

​

7. Termination

7.1  If you wish to terminate this agreement for any reason within 48 hours of being provided with the services then you

shall be entitled to a 15% refund of the amount paid. Such refund shall be payable at our sole discretion (acting

reasonably).

7.2  If you wish to terminate for any reason after 48 hours of being provided with the services then no refund will be

provided.

​

8. Disputes, Governing Law and Jurisdiction

8.1  In the event of a dispute concerning these terms and conditions, the parties shall use their reasonable endeavours to

resolve it as soon as practicable and in any event within 14 days.

8.2  These terms and conditions shall be governed by the law of Scotland and the courts of Scotland shall subject to clause 8.1 above have exclusive jurisdiction to settle any disputes which may arise out of or in connection with the Agreement.

Refurb Terms and Conditions

​

In the following terms and conditions the Company is REAL Property Scotland, and the Customer will be the entity named on the Invoice.

​

To protect your own interests, please read these terms and conditions carefully. If you are uncertain as to your rights under them or would like further explanation, please write to or telephone the Company, at the address or on the telephone number provided on the front of these terms and conditions. No additions to or variations to these terms and conditions shall be binding unless agreed in writing and signed by a representative of the Company. By making payment or allowing the Company access to the premises, you will be deemed to have accepted these terms and conditions.

The Company shall not be liable for any losses and/or delays that were unforeseeable to the parties when the contract was formed, or for any losses and/or delays not caused by the Company's breach of these terms and conditions or for any indirect or consequential losses.

The Customer will supply electricity for the use of power tools, free of charge.

The Customer will afford the Company all necessary access on the agreed installation date(s), including

access for refuge skips if necessary. Failure to provide access on said date(s) or requesting an alternative installation date within seven days of the services being provided may result in additional costs.

The Company neither claims nor guarantees to eliminate condensation. Condensation is a result of moisture within the air reaching its saturation point and the proper control of atmospheric conditions within the property is essential to minimise it.

The Company will provide the services using standard Company methods which may vary from time to time in line with Company policy

.

If the Company Surveyor finds evidence of existing problems or the need for alterations within the structure, the finishing of the property or the public utilities that are likely to give rise to additional costs during installation, the Company will advise the customer of this and of any estimated additional cost to be charged by the Company.

The Company will not be responsible for drawing attention to or remedying any defect that may exist in the premises before the date of installation or for any damage arising from a defect, unless the Customer decides to proceed with this.

The Company wishes to draw the Customers attention to the fact that imperfections are possible, and provided these are within reasonable tolerance, the Company will not be under any obligation to remedy.

The Company asks the Customer to inspect the services provided and inform the Company of any snagging requirements within 72 hours after completion of the works.

In the event of remedial work being required after installation, the Company shall carry out such work but only after payment of the full contract price, less a 2.5% deduction from total invoice balance. Any such sum deducted shall be due and payable immediately upon completion of remedial work.

Whilst every effort shall be made to avoid disturbing plasterwork, brickwork or roughcasting, the Company cannot be held responsible for any such damage. Every attempt will be made to ensure the new work matches in with your existing property, however an exact colour match cannot be guaranteed.

Unless specifically stated all materials removed during installation will be transported off site and disposed of by the Company. The Company will make every effort to ensure your waste is recycled in an environmentally friendly manner.

The Customer will be solely responsible for obtaining any Planning Permission or Building Warrant required. The Customer shall be responsible for all local authority fees incurred in respect of all submissions, successful or unsuccessful.

In the event of late payment the Company will charge interest on the full amount outstanding, calculated at the current Bank of England base rate plus 5%, as well as an administration fee of £500+VAT. Where necessary the Company will move quickly to recover the total amount due plus costs via our solicitors.

The Company does not offer any guarantee for the works.

Until payment in full has been made for the goods and installation all materials shall remain the property of the Company although the risk therein passes to the Customer upon practical completion of the installation.

16. Data Protection: The Company will use your information for administration, marketing and analysis. To help maintain the quality of our services the Company may also share your information with other carefully selected third parties. We or they may send you details of other goods and services via letter, telephone, email, or other reasonable means of communication.